Skip navigation

Construction of Works and Services to a 5 Residential Lot Development under Surrey Project No. 7815-0033-00.




Construction of Works and Services to a 5 Residential Lot Development
under Surrey Project No. 7815-0033-00.


Request for Expressions of Interest and Statements of Qualifications

The City invites responses from general contractors with specific expertise in land development site servicing interested in prequalifying for participation in the construction of works and services to serve a 5 single family residential lot development at 5948 - 5956 - 184 Street, Surrey, BC.

Project Deliverables
The works to be completed may include, but are not limited to, the following:
Clearing and grupping, lot grading, roadworks, asphalt overlay (at year-end maintenance period), street lighting, hydro/telephone/Shawcable installation, driveways, drainage works, storm detention facilities on lots, and sanitary sewer works and tie-ins and connections.

City expects contractor to commence the construction of the works and services by January 18, 2016.

RFEOI/SOQ Document for download: 
Construction of Works and Services - 5 Residential Lot Development (.pdf)
Schedule B - Form of Submission (.doc)

Addendum No. 1 (.pdf)
Issue Date:  December 1, 2015

If the City determines that an amendment is required to this RFEOI/SOQ, the City Representative will issue a written addendum by posting it on the BC Bid Website at (the “BC Bid Website”) and the City Website at (the “City Website”) that will form part of this RFEOI/SOQ. It is the responsibility of Respondents to check the BC Bid Website and the City Website for addenda. The only way this RFEOI/SOQ may be added to, or amended in any way, is by a formal written addendum. No other communication, whether written or oral, from any person will affect or modify the terms of this RFEOI/SOQ or may be relied upon by any Respondent. By delivery of a Submission, Respondent is deemed to have received, accepted and understood the entire RFEOI/SOQ including, any and all addenda.

All inquiries related to this RFEOI/SOQ should be directed in writing to the person named below.

Closing Date:

Prefer to receive Submissions on or before December 4, 2015.


Richard Oppelt
Purchasing Manager
Finance & Technology Department
Tel: (604) 590-7274

Status: Shortlisted have been notified.


















Business & Economic Development Menu